Welcome to RALINXT. By accessing or using our website and services, you agree to comply with and be bound by these Terms & Conditions. If you do not agree with any part of these terms, please refrain from using our website or services.
RALINXT provides digital marketing, website design and development, branding, CRM automation, SaaS development, AI solutions, lead generation, graphic design, video production, and related business growth services.
1. By using this website, you agree to these Terms & Conditions.
2. RALINXT provides digital marketing, web development, branding, CRM automation, SaaS development, AI solutions, and related services.
3. All project scopes, timelines, deliverables, and service details will be defined in individual proposals, quotations, contracts, or agreements.
4. Clients are responsible for providing accurate, complete, and timely information required for project completion.
5. Project timelines may be affected by delays in client feedback, approvals, content delivery, or third-party dependencies.
6. Pricing, fees, and payment terms will be outlined in project proposals, contracts, or invoices.
7. Additional work requested outside the agreed scope may incur additional charges.
8. All payments must be made according to the agreed payment schedule.
9. RALINXT reserves the right to suspend or terminate services for overdue or unpaid invoices.
10. Website content, graphics, logos, trademarks, designs, and intellectual property remain the property of their respective owners.
11. Clients retain ownership of all materials, content, and intellectual property provided by them.
12. Unless otherwise agreed in writing, RALINXT may showcase completed projects, designs, or case studies in its portfolio and marketing materials
13. RALINXT does not guarantee specific rankings, leads, sales, revenue growth, website traffic, or business outcomes.
14. Third-party platforms, software, tools, advertising networks, hosting providers, and services are subject to their own terms and policies.
15. Clients are responsible for maintaining and safeguarding login credentials, passwords, and access details provided after project completion.
16. RALINXT shall not be liable for losses, damages, delays, or disruptions caused by third-party outages, cyberattacks, hosting failures, software issues, natural disasters, or other circumstances beyond our control.
17. Users must not attempt unauthorized access, misuse, hacking, data extraction, disruption, or interference with our website, systems, or services.
18. RALINXT reserves the right to refuse, suspend, or terminate services for unlawful, fraudulent, unethical, abusive, or harmful activities.
19. Both RALINXT and the Client agree to maintain the confidentiality of proprietary, business, technical, financial, and personal information shared during the course of a project. 20. Confidential information shall not be disclosed to any third party without prior written consent unless required by law. 21. The confidentiality obligations shall remain in effect after project completion, cancellation, or termination.
22. Due to the nature of digital services and the resources invested, all payments made to RALINXT are non-refundable unless otherwise stated in a written agreement.
23. Deposits, consultation fees, setup fees, and completed work are strictly non-refundable.
24. Refund requests may be reviewed solely at the discretion of RALINXT under exceptional circumstances.
25. Clients may request cancellation of a project or service by providing written notice.
26. Any work completed prior to cancellation shall be billed and payable by the Client.
27. Payments made for completed milestones, consultations, and deposits are non-refundable.
28. RALINXT reserves the right to terminate services due to non-payment, breach of agreement, unlawful activity, or failure to provide required cooperation.
29. The Client agrees to indemnify, defend, and hold harmless RALINXT, its employees, contractors, partners, and affiliates from any claims, liabilities, damages, losses, costs, or expenses arising from:
* Content, materials, or information provided by the Client.
* Violation of intellectual property rights.
* Breach of these Terms & Conditions.
* Unlawful or unauthorized use of services.
30. RALINXT shall not be responsible for legal disputes, claims, or liabilities arising from client-provided content, products, services, or business activities.
31. To the maximum extent permitted by law, RALINXT's total liability for any claim relating to its services shall not exceed the amount paid by the Client for the specific service giving rise to the claim. 32. Under no circumstances shall RALINXT be liable for indirect, incidental, special, consequential, or punitive damages.
33. These Terms & Conditions shall be governed and interpreted in accordance with the laws of India. 34. Any disputes arising from these Terms shall be subject to the exclusive jurisdiction of the courts located in Tamil Nadu, India.
35. RALINXT reserves the right to update or modify these Terms & Conditions at any time. Updates will be posted on our website, and continued use of our website or services constitutes acceptance of the revised Terms.
36. For any questions regarding these Terms & Conditions, please contact RALINXT through the contact information provided on our website.
Copyright © 2026 Ralinxt. All rights reserved.
